Terms and Conditions

Purchase Terms and Conditions

TERMS AND CONDITIONS

The purchase order, together with these terms and conditions, and any attachments and exhibits, specifications, drawings, notes, instructions and other information, whether physically attached or incorporated by reference (collectively the “Purchase Order”), constitutes the entire and exclusive agreement between the Yanmar company (“Yanmar”) and the supplier (the “Supplier”) identified in the Purchase Order. Yanmar’s submission of the Purchase Order is conditioned on Supplier’s agreement that any terms different from or in addition to the terms of the Purchase Order, whether communicated orally or contained in any purchase order confirmation, invoice, acknowledgement, release, acceptance or other written correspondence, irrespective of the timing, shall not form a part of the Purchase Order, even if Supplier purports to condition its acceptance of the Purchase Order on Yanmar’s agreement to such different or additional terms. Supplier’s electronic acceptance, acknowledgement of this Purchase Order, or commencement of performance constitutes Supplier’s acceptance of these terms and conditions. The Purchase Order does not constitute a firm offer and may be revoked at any time prior to acceptance. Notwithstanding the foregoing, if a master agreement covering procurement of the Products or Work described in the Purchase Order exists between Supplier and Yanmar, the terms of such master agreement shall prevail over any inconsistent terms herein.

DEFINITIONS

2.1 “Deliverables” means the deliverables specified in the Purchase Order (and any Statement of Work) to be delivered on or before the Delivery Date.

2.2 “Delivery Date” means the date or dates specified in the Purchase Order by which the Supplier is required to deliver the Work.

2.3 “Harmful Code” means any software intentionally designed to (i) disrupt, disable, harm, or impede operation, or (ii) impair operation based on the lapse of time, including but not limited to viruses, worms, time bombs, time locks, drop-dead devices, access codes, security keys, back doors, or trap door devices.

2.4 “Intellectual Property Rights” means any and all tangible and intangible: (i) copyrights and other rights associated with works of authorship throughout the world, including but not limited to copyrights, neighboring rights, moral rights, and mask works, and all derivative works thereof; (ii) trademark and trade name rights and similar rights; (iii) trade secret rights; (iv) patents, designs, algorithms, utility models, and other industrial property rights, and all improvements thereto; (v) all other intellectual and industrial property rights (of every kind and nature throughout the world and however designated) whether arising by operation of law, contract, license, or otherwise; and (vi) all registrations, applications, renewals, extensions, continuations, divisions, or reissues thereof now or hereafter in force (including any rights in any of the foregoing).

2.5 “Products” means tangible goods specified in the Purchase Order to be delivered on or before the Delivery Date.

2.6 “Services” means the services that Supplier is to perform for Yanmar specified in the Purchase Order. 2.7 “Statement of Work” or “SOW” means the document specifying, without limitation, the scope, objective, and time frame of the Work that Supplier will perform for Yanmar.

2.8 “Subcontractor” means a third party performing Work under an agreement (a “Subcontract”) with Supplier.

2.9 “Supplier Personnel” means Supplier’s employees, consultants, agents, independent contractors and Subcontractors.

2.10 “Third Party Intellectual Property” means the Intellectual Property Rights of a third party which Supplier uses or incorporates into the Work.

2.11 “Work” means the Deliverables, Products and Services specified in the Purchase Order, including any SOW.

  1. DELIVERY

3.1 Time is of the essence in Supplier’s performance of its obligations under the Purchase Order. Supplier will immediately notify Yanmar if Supplier’s timely performance under the Purchase Order is delayed or is likely to be delayed. Yanmar’s acceptance of Supplier’s notice will not constitute Yanmar’s waiver of any of Supplier’s obligations.

3.2 If Supplier delivers Work after the Delivery Date, Yanmar may reject such Work.

3.3 Yanmar will hold any Work rejected under this Purchase Order at Supplier’s risk and expense, including storage charges, while awaiting Supplier’s returns shipping instructions. Supplier will bear all return shipping charges, including without limitation, insurance charges Yanmar incurs on Supplier’s behalf. Yanmar may, in its sole discretion, destroy or sell at a public or private sale any rejected Work for which Yanmar does not receive return shipping instructions within a reasonable time, and apply the proceeds, if any, first toward any storage charges.

3.4 Supplier will preserve, pack, package and handle the Deliverables and Products so as to protect the Deliverables and Products from loss or damage and in accordance with best commercial practices in the absence of any specifications Yanmar may provide. Without limiting the foregoing, Supplier shall observe the requirements of any local laws and regulations relating to hazardous work, including, without limitation, with respect to its accompanying information, packing, labeling, reporting, carriage and disposal.

3.5 Supplier will include with each delivery of Products a packing list identifying the Purchase Order number, the Yanmar part number for each of the Products (if applicable), a description and the quantity of each of the Products, and the date of shipment.

3.6 Unless Yanmar expressly instructs otherwise, Supplier will deliver all Work to Yanmar’s plant at the address set forth in the Purchase Order. Seller assumes responsibility for all shipping and delivery charges including, without limitation, customs, duties, costs, taxes and insurance. Risk of loss for the Deliverables and Products does not pass to Yanmar until acceptance in accordance with Section 6.

  1. PRICE AND PAYMENT

4.1 Unless otherwise specified in the Purchase Order, the price for the Work includes all taxes and other charges such as shipping and delivery charges, duties, customs, tariffs, imposts and government-imposed surcharges. Supplier will, at Yanmar’s request, break-out from the price all such taxes and other charges, in its invoices. Supplier shall use its best efforts to assist Yanmar in all legal efforts to minimize the taxes resulting from the performance of this Purchase Order.

4.2 Yanmar will pay Supplier the price in accordance with the payment terms set forth in the Purchase Order following the later of: (i) the Delivery Date; (ii) the date of Yanmar’s acceptance of all of the Work; or (iii) Yanmar’s receipt of a properly prepared invoice. A properly prepared invoice must include the Purchase Order number and, if required in the Purchase Order, Supplier’s certification of conformance of the Work to the requirements. Payment will be in the currency of the country in which the Yanmar entity or affiliate identified in the Purchase Order is located, and if the price set forth in the Purchase Order is not in the local currency, then Yanmar will determine the local currency equivalent of the price as of date of payment. Yanmar may, at any time, set-off any amounts Supplier owes Yanmar against any amounts Yanmar owes to Supplier or any of its affiliated companies.

  1. OWNERSHIP AND LICENSE

5.1 Yanmar is the sole and exclusive owner of all Deliverables. Supplier irrevocably assigns and transfers to Yanmar all of its worldwide right and title to, and interest in, the Deliverables, including all associated Intellectual Property Rights.

5.2 Notwithstanding Section 5.1, Supplier grants to Yanmar a non-exclusive, worldwide, royalty-free, irrevocable, perpetual, transferable, sublicenseable license to any Intellectual Property Rights in the Deliverables which arose outside the scope of the Purchase Order to the extent necessary for Yanmar to exercise its rights in the Deliverables as reasonably contemplated by the Purchase Order.

5.3 Supplier grants to Yanmar a non-exclusive, worldwide, royalty-free, irrevocable, perpetual, transferable, sublicenseable license to any Intellectual Property Rights in Products or Services which are necessary for Yanmar to use, import, copy, execute, reproduce, display, perform, and distribute copies of and modify (including creating improvements and derivative works based on) the Products or Services.

  1. INSPECTION AND ACCEPTANCE

Yanmar may reject any or all of the Work which does not conform to the applicable requirements within 10 business days of Supplier’s delivery of the Work. At Yanmar’s option, Yanmar may (i) return the non-conforming Work to Supplier for a refund or credit; (ii) requires Supplier to replace the non-conforming Work; or (iii) repair the non-conforming Work so that it meets the requirements. As an alternative to (i) through (iii), Yanmar may accept the non-conforming Work conditioned on Supplier providing a refund or credit in an amount Yanmar reasonably determines to represent the diminished value of the non-conforming Work. Yanmar’s payment to Supplier for Work prior to Yanmar’s timely rejection of such Work as non-conforming will not be deemed as acceptance by Yanmar.

  1. CHANGES

7.1 As used in this Section 7, “Change” means a change Yanmar directs or causes within the general scope of this Agreement, the applicable SOW or both.

7.2 Yanmar, by written order (“Change Order”), may make Changes in accordance with this Section 7.

7.3 If Supplier asserts that Yanmar has directed or caused a Change to the cost of or time for performance for which Yanmar has not issued a Change Order, Supplier will promptly notify Yanmar in writing of the Change, providing (i) a description of the action or inaction asserted to have caused the Change; (ii) an estimate of the equitable adjustment that would be required for Supplier to perform the Changed Work; and (iii) a date no less than 30 days from the date of notice by which Yanmar must respond to Supplier’s notice so that Supplier may proceed with the Work unchanged. Yanmar will evaluate Supplier’s notice of Change in good faith, and if Yanmar agrees that it has made a constructive change, Yanmar will issue a Change Order to Supplier.

7.4 Supplier shall, as promptly as practicable, after giving the notice of the Change, or within 10 days of receiving a Change Order, submit a request for equitable adjustment specifying the adjustment in the price or time for performance resulting from the Change.

7.5 The parties shall negotiate an amendment to the applicable SOW to incorporate a Change Order providing for an equitable adjustment to the price, time for performance, or both.

7.6 Supplier will proceed with the Changed Work as directed, notwithstanding that the parties have not negotiated the amendment to this Agreement or the applicable SOW to incorporate the equitable adjustment.

  1. REPRESENTATIONS AND WARRANTIES

8.1 Supplier represents and warrants that (i) it has the full power to enter into the Purchase Order and to perform its obligations under the Purchase Order; (ii) it has the right and unrestricted ability to assign the Work to Yanmar including, without limitation, the right to assign any Work performed by Supplier Personnel and Subcontractors; (iii) the Work, and Yanmar’s use of the Work, do not and will not infringe upon any third party’s Intellectual Property Rights, right of publicity or privacy, or any other proprietary rights, whether contractual, statutory or common law; (iv) Supplier will not disclose to Yanmar, bring onto Yanmar’s premises, or induce Yanmar to use any confidential or proprietary information that belongs to anyone other than Yanmar or Supplier which is not covered by a non-disclosure agreement between Yanmar and Supplier; (v) Software supplied by Supplier does not contain any Harmful Code; (vi) Supplier’s Work conforms to Yanmar’s specifications, Supplier’s quotation or proposal, and Supplier’s brochures or catalogs, and if none of the foregoing is applicable, then such Work is suitable for the intended use; and (vii) no Products contain or include components (a) containing PCB’ (polychlorinated biphenyls) chemical substances, (b) manufactured using a cadmium plating process or contain a chemical substance or mixture that is or becomes subject to a reporting requirement under Section 8(e) of the Toxic Substances Control Act, 15 U.S.C. Section 2607(e), as in effect at time of shipment.

8.2 Yanmar warrants and represents to Supplier that it has the full power to enter into the Purchase Order and to perform its obligations under the Purchase Order.

8.3 TO THE EXTENT ALLOWED BY APPLICABLE LAW, NO OTHER WARRANTIES ARE MADE, EITHER EXPRESSED OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.

  1. ASSIGNMENT AND SUBCONTRACTING

9.1 Supplier may not assign any of its rights or delegate any of its obligations under the Purchase Order without Yanmar’s prior written consent, which Yanmar will not unreasonably withhold. Yanmar may, at its option, void any attempted assignment or delegation undertaken without Yanmar’s prior written consent.

9.2 Supplier may not subcontract any of its rights or obligations under the Purchase Order without Yanmar’s prior written consent. If Yanmar consents to the use of a Subcontractor, Supplier will: (i) guarantee and will remain liable for the performance of all subcontracted obligations; (ii) indemnify Yanmar for all damages and costs of any kind, subject to the limitations in Section 12 (Indemnification), incurred by Yanmar or any third party and caused by the acts and omissions of Supplier’s Subcontractors’ and (iii) make all payments to its Subcontractors. If Supplier fails to timely pay a Subcontractor for work performed, Yanmar will have the right, but not the obligation, to pay the Subcontractor and offset any amount due to Supplier by any amount paid to the Subcontractor. Supplier will defend, indemnify and hold Yanmar harmless for all damages and costs of any kind, without limitation, incurred by Yanmar and caused by Supplier’s failure to pay a Subcontractor.

9.3 To the extent allowed by applicable law, no person who is not a party to Purchase Order shall be entitled to enforce or take the benefit of any of its terms whether as a result of applicable legislation, custom or otherwise.

  1. TERM AND TERMINATION

10.1 The Purchase Order will remain in effect with respect to any SOW already issued prior to expiration of the term of the Purchase Order until such SOW is either terminated or the Work is completed and accepted.

10.2 Yanmar may terminate this Purchase Order, any SOW, or both at any time, for no reason or for any reason, upon 15 days written notice to Supplier. Upon receipt of notice of such termination, Supplier will inform Yanmar of the extent to which it has completed performance as of the date of the notice, and Supplier will collect and deliver to Yanmar whatever Work then exists. Yanmar will pay Supplier for all Work performed and accepted through the effective date of the termination, provided that Yanmar will not be obligated to pay any more than the payment that would have become due had Supplier completed and Yanmar had accepted the Work. Yanmar will have no further payment obligation in connection with any termination.

10.3 Either party may terminate the Purchase Order, any SOW or both, immediately by delivering written notice to the other party upon the occurrence of any of the following events: (i) a receiver is appointed for either party or its property; (ii) either makes a general assignment for the benefit of its creditors; (iii) either party commences, or has commenced against it, proceedings under any bankruptcy, insolvency or debtor’s relief law, if such proceedings are not dismissed within 60 days; or (iv) either party is liquidating, dissolving, or ceasing to do business in the ordinary course.

10.4 Yanmar may immediately terminate the Purchase Order upon written notice to Supplier if there is a change in ownership representing 20 percent or more of the equity ownership of Supplier.

10.5 Either party may terminate this Purchase Order, any SOW or both, immediately by delivering written notice to the other party for any material breach not cured within 30 days of receipt of notice of the breach. Yanmar shall have no further payment obligation to Supplier under any terminated SOW if Yanmar terminates the SOW under this Section 10.5.

10.6 Any obligations or duties which, by their nature, extend beyond the expiration or termination of the Purchase Order shall survive the expiration or termination of the Purchase Order.

  1. CONFIDENTIAL INFORMATION AND PUBLICITY

11.1 If Yanmar and Supplier have entered into a Non-Disclosure Agreement (“NDA”) which covers disclosure of confidential information under the Purchase Order, and if the term of the NDA expires before the expiration or termination of the Purchase Order, then the term of the NDA shall be automatically extended to match the term of the Purchase Order.

11.2 The parties shall treat the terms, conditions, and existence of the Purchase Order as Confidential Information as defined in the NDA.

11.3 Supplier shall obtain Yanmar’s written consent prior to any publication, presentation, public announcement, or press release concerning its relationship as a supplier to Yanmar.

  1. INDEMNIFICATION

12.1 As used in this Section 12, a “Claim” is any claim, demand, loss, damage, liability, cost or expense (including professional fees and costs as incurred) for which one party (the “Indemnifying Party”) may be obligated to defend, indemnify and hold the other party (the “Indemnified Party”) harmless.

12.2 Supplier shall defend, indemnify and hold Yanmar harmless from and against any and all Claims as incurred, arising out of or in connection with any (i) act or omission of Supplier (including its Subcontractors) in the performance of the Work; or (ii) any infringement of a third party’s Intellectual Property Rights or any other rights.

12.3 Yanmar shall indemnify and hold Supplier harmless from and against any and all Claims as incurred, arising out of or in connection with: (i) Supplier’s use of Yanmar’s products or services in connection with the Work; (ii) Supplier’s use of information or materials provided to Supplier by Yanmar; or (iii) infringement a third party’s Intellectual Property Rights or any other rights resulting from Supplier’s adherence to Yanmar’s written instructions.

12.4 Each party will indemnify and hold the other party harmless from and against any and all Claims, as incurred, arising out of any negligent or willful acts or omissions of the Indemnifying Party which results in personal injury (including death) or damage to tangible property (not including lost or damaged data).

12.5 The Indemnified Party will provide the Indemnifying Party with prompt written notice of the Claim and permit the Indemnifying Party to control the defense, settlement, adjustment, or compromise of any Claim. The Indemnified Party may employ counsel at its own expense to assist it with respect to any Claim. The Indemnified Party will have no authority to settle any Claim on the Indemnified Party’s behalf.

12.6 If a third party enjoins or interferes with Yanmar’s use of any Work, then in addition to Supplier’s obligations under Section 12.2, Supplier will use its best efforts to (i) obtain any licenses necessary to permit Yanmar to continue to use the Work; (ii) replace or modify the Work as necessary to permit Yanmar to continue to use of the Work; or if (i) and (ii) are not commercially reasonable, then (iii) promptly refund to Yanmar the amount paid for any Work for which a third party enjoins or interferes with Yanmar’s use of the Work.

12.7 Nothing in this Section shall limit any other remedy of the parties.

  1. LIABILITY

13.1 NOTWITHSTANDING ANYTHING ELSE IN THE PURCHASE ORDER OR OTHERWISE, YANMAR WILL NOT BE LIABLE TO SUPPLIER WITH RESPECT TO THE SUBJECT MATTER OF THE PURCHASE ORDER UNDER ANY CONTRACT, NEGLIGENCE, STRICT LIABILITY OR OTHER LEGAL OR EQUITABLE THEORY FOR ANY AMOUNTS IN EXCESS IN THE AMOUNT YANMAR PAID TO SUPPLIER IN THE SIX MONTHS PRECEDING THE EVENT OR CIRCUMSTANCE GIVING RISE TO SUCH LIABILITY.

13.2 IN NO EVENT WILL YANMAR BE LIABLE TO SUPPLIER FOR ANY INCIDENTAL, INDIRECT, SPECIAL, CONSEQUENTIAL DAMAGES OR LOSS OF PROFITS ARISING OUT OF, OR IN CONNECTION WITH, THE PURCHASE ORDER, WHETHER OR NOT YANMAR WAS ADVISED OF THE POSSIBILITY OF SUCH DAMAGE.

13.3 THE LIMITATIONS WILL APPLY NOTWITHSTANDING ANY FAILURE OF ESSENTIAL PURPOSE OF ANY LIMITED REMEDY PROVIDED HEREIN. NOTHING IN THE PURCHASE ORDER LIMITS EITHER PARTY’S LIABILITY FOR BODILY INJURY OF A PERSON, DEATH, OR PHYSICAL DAMAGE TO PROPERTY OR ANY LIABILITY WHICH CANNOT BE EXCLUDED UNDER APPLICABLE LAW.

  1. INSURANCE

Supplier will secure and maintain insurance providing coverage for liabilities to third parties for bodily injury (personal injury) and damage to property in amounts sufficient to protect Yanmar in the event of such injury or damage, and will be in compliance with any and all laws, regulations or orders addressing the liabilities of an employer to its employees for injuries and disease suffered in connection with employment. Supplier further will maintain such additional types and limits of insurance as is customary for a company of similar size and similar operations to Supplier in the jurisdiction or jurisdictions in which Supplier’s operations take place.

  1. COMPLIANCE WITH LAWS

Supplier represents and warrants that it will comply with all applicable local and national laws and regulations pertaining to its performance of its obligations under this Purchase Order. In particular and without limitation, Supplier shall not act in any fashion or take any action that will render Yanmar liable for a violation of the U.S. Foreign Corrupt Practices Act (“FCPA”), which prohibits the offering, giving or promising to offer or give, directly or indirectly, money or anything of value to any official of a government, political party or instrumentality to assist it or Yanmar in obtaining or retaining business or in carrying out the Services. Supplier’s failure to comply with the FCPA shall constitute a material breach of this Purchase Order.

  1. GOVERNING LAW

The Purchase Order will be construed in accordance with, and all disputes will be governed by, the laws of the State of Georgia, without regard to its conflict of laws rules. The parties specifically waive application of the UN Convention on Contracts for the International Sale of Goods. Supplier irrevocably consents to the personal jurisdiction of the state and federal courts in and for Bartow County, Georgia, and irrevocably waives any claim it may have that any proceedings brought in such courts have been brought in an inconvenient forum.

  1. GENERAL

17.1 Any notice to be given under the Purchase Order will be in writing and addressed to the party at the address stated in the front of the Purchase Order. Notices will be deemed given and effective (i) if personally delivered, upon delivery, (ii) if sent by an overnight service with tracking capabilities, upon receipt; (iii) if sent by fax or electronic mail, at such time as the party which sent the notice receives confirmation of receipt by the applicable method of transmittal; or (iv) if sent by certified or registered mail, within five days of deposit in the mail.

17.2 If there is a conflict between or among the Purchase Order and any documents attached to and incorporated by reference, the conflict will be resolved as follows:

17.2.1 A conflict between the terms of the Purchase Order and those set forth in an exhibit or hyperlink will be resolved in favor of the Purchase Order.

17.2.2 A conflict between the terms of the Purchase Order and those set forth in an SOW will be resolved in favor of the SOW.

17.2.3 A conflict between the terms of an exhibit or hyperlink and those set forth in an SOW will be resolved in favor of the SOW.

17.3 If any court of competent jurisdiction holds that any provision of the Purchase Order is illegal, invalid, or unenforceable, the legality, validity, and enforceability of the remaining provisions of the Purchase Order will not be affected or impaired, and all remaining terms of this Purchase Order remain in full force and effect, provided that this provision shall not be applied to defeat the intent of the parties.

17.4 A party’s election not to insist on strict performance of any requirement of the Purchase Order will not operate or be construed to waive any future omission or breach, or any other provision of the Purchase Order.

Additional Terms and Conditions

INCREASES IN FREIGHT, INSURANCE, DUTY, ETC.

This Contract is based upon the present rates for freight, insurance, government tariffs, duties, taxes, impost, assessments, and other levies existing here and abroad. Any increase therein, whether caused by change in duty classifications, valuation or otherwise, or any other government tariff, tax imposts, assessment or other levy that may thereafter be imposed upon the merchandise (hereinafter referred to as Goods) which is the subject of this sale or upon the sale thereof, is to be added to and become a part of the Contract price and paid by Buyer. All the above provisions shall apply not only to such levies as are imposed by the United States or any other country, but also to such as are imposed by any State, County, City, Municipality, other political subdivision or public authority.

  1. MULTIPLE SHIPMENTS – SEPARATE CONTRACTS

If the Contract provides for multiple shipment or delivery each such shipment or delivery hereunder shall be construed and considered as a separate sale under the terms and conditions of this Contract, and Buyer agrees to accept and pay for each such shipment or delivery as provided herein. Should Buyer fail to accept or pay for each such shipment or delivery, Seller may without prejudice to any other lawful remedy, defer further shipments or deliveries until acceptance thereof by Buyer of until payment is made by Buyer or at its option Seller may without liability whatsoever terminate this Contract as to any unaccepted or undelivered portion thereof, as well as any other outstanding Contract with Buyer, and Buyer shall be responsible for any expense and losses sustained by Seller by so doing.

  1. OWNERSHIP

Delivery of Goods by the Seller to the carrier at the shipping point shall constitute delivery to the Buyer. Upon delivery of Goods to the carrier, title of Goods and risk of loss shall pass to the Buyer subject to the Seller’s right of stoppage in transit to secure payment of the purchase price for Goods.

  1. NON-DELIVERY OR DELAY BEYOND SELLER’S CONTROL

If any shipment or delivery hereunder shall be delayed through any act or neglect of the carrier or any other person, including subcontractors, manufacturers and suppliers of the Seller, or by any embargo, hostilities, war civil disturbance, strike, fire, accident, government seizure or requisition force majeure, or by reason of any other cause whatsoever, whether domestic or foreign, whether direct or indirect, beyond the reasonable control of Seller. Seller shall not be responsible for any delay in shipment or for non-delivery of all or any part of Goods and Seller may prorate the quantity deliverable at its option without liability hereunder. In the even that Seller elects to prorate the quantity of deliverable, this Contract as so prorated shall be binding upon Seller and Buyer.

Seller may make or resume shipment or delivery upon removal of such cause or causes of delay: provided, however that if such delay of non-delivery or non-shipment is or shall be for more than ninety (90) days from the scheduled date of delivery or shipment, the whole or remainder of the Contract may be cancelled by Seller, without liability hereunder, upon notice in writing of electron to cancel the same.

  1. DISCLAIMER OF WARRANTIES

a. SELLER MAKES NO WARRANTIES OR REPRESENTATIONS, EXPRESS OR IMPLIED AS TO THE MERCHANTABILITY OF THE GOODS, THEIR FITNESS FOR ANY PARTCIULAR PURPOSE, OR THEIR CONDITION OR QUALITY, EXCEPT AS OTHERWISE SPECFICALLY PROVIDED HERIN.

b. Buyer shall assume all risk and liability resulting from the use by it in manufacturing or construction processing of Goods delivered under the Contract or by its use of such Goods in combination with other substances.

c. Seller shall not be liable for any incidental or consequential damages caused by its breach of any of the terms in this Contract.

  1. MODIFICATION OF LINE OF CREDIT

This Contract is subject to a limit of credit of Buyer determinable at any time by Seller, his agent or factor. Seller reserves the right to limit or cancel Buyer’s credit line upon notification to Buyer. If Buyer exceeds his line of credit or if in the opinion of the Seller, his agent or factor, the financial condition of Buyer warrants such action, Buyer, upon written demand by Seller, and notwithstanding the selling terms stated on the face hereof, shall pay cash or anticipate payment before delivery of any shipment. Upon failure by Buyer to make such payment within 10 days, Seller shall have, in addition to the other rights set forth in this Contract or granted to it by law, the right to cancel the Contract, bill all or any part of the undelivered merchandise to Buyer and withhold delivery until payment is received or sell all or any part of the undelivered merchandise at public or private sale, holding Buyer responsible for any financial loss incurred.

  1. PAYMENT

All monies due to Seller arising under this Contract shall be payable in lawful currency of the United States. In the event that Seller advances any sums in a foreign currency which is reimbursable to Seller by Buyer under this Contract. Buyer shall pay to Seller the equivalent of the amount advance, in United States currency at the rate of exchange current at the time of such advance.

  1. INTEREST CHARGE

If Buyer fails to make payment on the date stated herein, Buyer shall be responsible for the interest on the unpaid balance until paid in full.

  1. CLAIMS AND ALLOWANCES

Seller shall not be liable for normal manufacturing imperfections nor for customary or reasonable variations from specifications. Claims of any kind or nature, except for latent defects, are specifically barred unless made in writing by registered mail within 30 days after delivery of Goods to Buyer or its agent at the destination. Claims for latent defects are barred unless presented in writing by registered mail within 60 days after date of delivery to Buyer. The limit of liability of Seller for rejected merchandise shall be the difference in value on Contract date of delivery between goods specified and goods actually delivered. The limit of liability of Seller for non-delivery shall be the difference, if any, between the Contract price and the fair market price on the Contract date of delivery of the Goods to be delivered. In no event shall Buyer be entitled to claim any other damages or any consequential damages to rejected Goods, defective Goods, late delivery or non-delivery, and in no instances shall damages include profit on contemplated use or profit of any description.

  1. PATENT VIOLATIONS

Buyer shall indemnify, hold harmless and defend Seller or any of Seller’s distributors or suppliers from and against any and all suits, actions, legal proceedings, demands, damages, costs, expenses, and attorney’s fees resulting from any claim that Buyer has infringed any patent, trademark, design, copyright, utility model or any other industrial property right of the United States or any foreign country, existing or hereafter issued and Buyer shall defend or settle at its own expense any suit, action or proceeding in which Seller or any of Seller’s distributors or suppliers are made defendant for such infringement; and Buyer further agrees to pay any and all loss and damage cause thereby to Seller or any of Seller’s distributors or suppliers, including, but not limited to the payment and discharge of any and all judgments or decrees, which may be rendered in any such suit, action or proceeding against such defendants.

  1. TERMINATION

Seller reserves the right to cancel this Contract partially or entirely, without notice, in the event Buyer fails to make payments as specified or breaches any other terms and conditions of this Contract. Seller may forthwith cancel this Contract on occurrence of any of the following: insolvency of Buyer, filing by Buyer of a voluntary petition in bankruptcy, filing of an involuntary petition to have Buyer declared bankrupt; appointment of a receiver or trustee for Buyer; execution by Buyer of an assignment or composition arrangement for the benefit of creditors; filing of a voluntary or involuntary petition for corporate reorganization of Buyer; or initiation by any party of any other proceeding involving Buyer as debtor under the Bankruptcy Act, as amended in the event of any cancellation under this paragraph. Seller without prejudice to any other rights available to it for breach of this Contract, shall have the right (a) to refuse to deliver any additional Goods; (b) to recover from Buyer the Contract price of all Goods delivered and freight, storage, handling, and other expenses incurred by Seller; (c) to sell the cancelled or terminated Goods elsewhere, and charge Buyer with any resultant losses.

  1. ATTORNEY’S FEES

If Seller commences an action against Buyer to enforce any of the terms hereof or because of the breach by Buyer of any of the terms hereof, or for the recovery of any payments due hereunder, Buyer shall pay to Seller reasonable attorney’s fees and expenses, and the right to such attorney’s fees and expenses shall be deemed to have accrued on the commencement of such action and shall be enforceable whether or not such action is prosecuted to judgment.

  1. LIMITATION OF ACTION

The Buyer agrees and covenants that, regardless of any otherwise applicable statute of limitations, any claim or action brought by Buyer under this Contract or pertaining to the Goods purchased hereunder shall be commenced within one (1) year from the date of transfer of ownership of the Goods to Buyer.

  1. ASSIGNMENT

Buyer shall neither assign any right nor delegate any duties under this Contract nor any monies due hereunder without the prior written consent of Seller’s authorized representatives. This prohibition of assignment and delegation extends to all assignments and delegations that may lawfully be prohibited by agreement.

  1. APPLICABLE LAWS

This Contract is made and to be performed in the Sates of Illinois. Unless otherwise specifically agreed this Contract and any disputes thereunder shall be governed by the laws of the State of Illinois.

  1. ENTIRE CONTRACT

This Contract supersedes all other agreements, representations, understandings, prior course of dealing, trade usage or course of performance, verbal or written and constitutes the entire Contract between Buyer and Seller, except that, if parties hereto have entered into an overriding agreement which is identified on the front hereof, the terms and conditions therein set forth shall be incorporated herein by references as though specifically set forth herein. Any provision herein which is inconsistent with the provisions of said overriding agreement is hereby amended to conform to said overriding agreement.

  1. MODIFICATION AND WAIVER

Any alterations or modifications of this Contract shall be by mutual agreement of the parties and shall not be binding on Seller unless made in writing and agreed to by a duty authorized official of Seller.

No claim or right arising out of breach of this Contract can be discharged in whole or in part by waiver of renunciation of the claim or right unless the waiver or renunciation is in writing and signed by Seller.

  1. REMEDIES

The remedies herein reserved to Seller shall be cumulative and additional to any other or further remedies provided in law or equity.

Additional Terms and Conditions Applicable to Any Purchase of Yanmar Goods

By the placement of electronic order and purchase of any goods sold by Yanmar (“Seller”) and purchased by customer (“Buyer”) through the Yanmar web portal, Buyer acknowledges and agrees that Buyer is entering into Contract with Seller, and accepts and agrees to the following Terms and Conditions applicable to Buyer’s purchase hereunder:

INCREASES IN FREIGHT, INSURANCE, DUTY, ETC.

This Contract is based upon the present rates for freight, insurance, government tariffs, duties, taxes, impost, assessments, and other levies existing here and abroad. Any increase therein, whether caused by change in duty classifications, valuation or otherwise, or any other government tariff, tax imposts, assessment or other levy that may thereafter be imposed upon the merchandise (hereinafter referred to as Goods) which is the subject of this sale or upon the sale thereof, is to be added to and become a part of the Contract price and paid by Buyer. All the above provisions shall apply not only to such levies as are imposed by the United States or any other country, but also to such as are imposed by any State, County, City, Municipality, other political subdivision or public authority.

MULTIPLE SHIPMENTS – SEPARATE CONTRACTS

If the Contract provides for multiple shipment or delivery each such shipment or delivery hereunder shall be construed and considered as a separate sale under the terms and conditions of this Contract, and Buyer agrees to accept and pay for each such shipment or delivery as provided herein. Should Buyer fail to accept or pay for each such shipment or delivery, Seller may without prejudice to any other lawful remedy, defer further shipments or deliveries until acceptance thereof by Buyer of until payment is made by Buyer or at its option Seller may without liability whatsoever terminate this Contract as to any unaccepted or undelivered portion thereof, as well as any other outstanding Contract with Buyer, and Buyer shall be responsible for any expense and losses sustained by Seller by so doing.

OWNERSHIP

Delivery of Goods by the Seller to the carrier at the shipping point shall constitute delivery to the Buyer. Upon delivery of Goods to the carrier, title of Goods and risk of loss shall pass to the Buyer subject to the Seller’s right of stoppage in transit to secure payment of the purchase price for Goods.

NON-DELIVERY OR DELAY BEYOND SELLER’S CONTROL

If any shipment or delivery hereunder shall be delayed through any act or neglect of the carrier or any other person, including subcontractors, manufacturers and suppliers of the Seller, or by any embargo, hostilities, war civil disturbance, strike, fire, accident, government seizure or requisition force majeure, or by reason of any other cause whatsoever, whether domestic or foreign, whether direct or indirect, beyond the reasonable control of Seller. Seller shall not be responsible for any delay in shipment or for non-delivery of all or any part of Goods and Seller may prorate the quantity deliverable at its option without liability hereunder. In the even that Seller elects to prorate the quantity of deliverable, this Contract as so prorated shall be binding upon Seller and Buyer.

Seller may make or resume shipment or delivery upon removal of such cause or causes of delay: provided, however that if such delay of non-delivery or non-shipment is or shall be for more than ninety (90) days from the scheduled date of delivery or shipment, the whole or remainder of the Contract may be cancelled by Seller, without liability hereunder, upon notice in writing of electron to cancel the same.

DISCLAIMER OF WARRANTIES

a. SELLER MAKES NO WARRANTIES OR REPRESENTATIONS, EXPRESS OR IMPLIED AS TO THE MERCHANTABILITY OF THE GOODS, THEIR FITNESS FOR ANY PARTCIULAR PURPOSE, OR THEIR CONDITION OR QUALITY, EXCEPT AS OTHERWISE SPECFICALLY PROVIDED HERIN.

b. Buyer shall assume all risk and liability resulting from the use by it in manufacturing or construction processing of Goods delivered under the Contract or by its use of such Goods in combination with other substances.

c. Seller shall not be liable for any incidental or consequential damages caused by its breach of any of the terms in this Contract.

MODIFICATION OF LINE OF CREDIT

This Contract is subject to a limit of credit of Buyer determinable at any time by Seller, his agent or factor. Seller reserves the right to limit or cancel Buyer’s credit line upon notification to Buyer. If Buyer exceeds his line of credit or if in the opinion of the Seller, his agent or factor, the financial condition of Buyer warrants such action, Buyer, upon written demand by Seller, and notwithstanding the selling terms stated on the face hereof, shall pay cash or anticipate payment before delivery of any shipment. Upon failure by Buyer to make such payment within 10 days, Seller shall have, in addition to the other rights set forth in this Contract or granted to it by law, the right to cancel the Contract, bill all or any part of the undelivered merchandise to Buyer and withhold delivery until payment is received or sell all or any part of the undelivered merchandise at public or private sale, holding Buyer responsible for any financial loss incurred.

PAYMENT

All monies due to Seller arising under this Contract shall be payable in lawful currency of the United States. In the event that Seller advances any sums in a foreign currency which is reimbursable to Seller by Buyer under this Contract. Buyer shall pay to Seller the equivalent of the amount advance, in United States currency at the rate of exchange current at the time of such advance.

INTEREST CHARGE

If Buyer fails to make payment on the date stated herein, Buyer shall be responsible for the interest on the unpaid balance until paid in full.

CLAIMS AND ALLOWANCES

Seller shall not be liable for normal manufacturing imperfections nor for customary or reasonable variations from specifications. Claims of any kind or nature, except for latent defects, are specifically barred unless made in writing by registered mail within 30 days after delivery of Goods to Buyer or its agent at the destination. Claims for latent defects are barred unless presented in writing by registered mail within 60 days after date of delivery to Buyer. The limit of liability of Seller for rejected merchandise shall be the difference in value on Contract date of delivery between goods specified and goods actually delivered. The limit of liability of Seller for non-delivery shall be the difference, if any, between the Contract price and the fair market price on the Contract date of delivery of the Goods to be delivered. In no event shall Buyer be entitled to claim any other damages or any consequential damages to rejected Goods, defective Goods, late delivery or non-delivery, and in no instances shall damages include profit on contemplated use or profit of any description.

PATENT VIOLATIONS

Buyer shall indemnify, hold harmless and defend Seller or any of Seller’s distributors or suppliers from and against any and all suits, actions, legal proceedings, demands, damages, costs, expenses, and attorney’s fees resulting from any claim that Buyer has infringed any patent, trademark, design, copyright, utility model or any other industrial property right of the United States or any foreign country, existing or hereafter issued and Buyer shall defend or settle at its own expense any suit, action or proceeding in which Seller or any of Seller’s distributors or suppliers are made defendant for such infringement; and Buyer further agrees to pay any and all loss and damage cause thereby to Seller or any of Seller’s distributors or suppliers, including, but not limited to the payment and discharge of any and all judgments or decrees, which may be rendered in any such suit, action or proceeding against such defendants.

TERMINATION

Seller reserves the right to cancel this Contract partially or entirely, without notice, in the event Buyer fails to make payments as specified or breaches any other terms and conditions of this Contract. Seller may forthwith cancel this Contract on occurrence of any of the following: insolvency of Buyer, filing by Buyer of a voluntary petition in bankruptcy, filing of an involuntary petition to have Buyer declared bankrupt; appointment of a receiver or trustee for Buyer; execution by Buyer of an assignment or composition arrangement for the benefit of creditors; filing of a voluntary or involuntary petition for corporate reorganization of Buyer; or initiation by any party of any other proceeding involving Buyer as debtor under the Bankruptcy Act, as amended in the event of any cancellation under this paragraph. Seller without prejudice to any other rights available to it for breach of this Contract, shall have the right (a) to refuse to deliver any additional Goods; (b) to recover from Buyer the Contract price of all Goods delivered and freight, storage, handling, and other expenses incurred by Seller; (c) to sell the cancelled or terminated Goods elsewhere, and charge Buyer with any resultant losses.

ATTORNEY’S FEES

If Seller commences an action against Buyer to enforce any of the terms hereof or because of the breach by Buyer of any of the terms hereof, or for the recovery of any payments due hereunder, Buyer shall pay to Seller reasonable attorney’s fees and expenses, and the right to such attorney’s fees and expenses shall be deemed to have accrued on the commencement of such action and shall be enforceable whether or not such action is prosecuted to judgment.

LIMITATION OF ACTION

The Buyer agrees and covenants that, regardless of any otherwise applicable statute of limitations, any claim or action brought by Buyer under this Contract or pertaining to the Goods purchased hereunder shall be commenced within one (1) year from the date of transfer of ownership of the Goods to Buyer.

ASSIGNMENT

Buyer shall neither assign any right nor delegate any duties under this Contract nor any monies due hereunder without the prior written consent of Seller’s authorized representatives. This prohibition of assignment and delegation extends to all assignments and delegations that may lawfully be prohibited by agreement.

APPLICABLE LAWS

This Contract is made and to be performed in the Sates of Illinois. Unless otherwise specifically agreed this Contract and any disputes thereunder shall be governed by the laws of the State of Illinois.

ENTIRE CONTRACT

This Contract supersedes all other agreements, representations, understandings, prior course of dealing, trade usage or course of performance, verbal or written and constitutes the entire Contract between Buyer and Seller, except that, if parties hereto have entered into an overriding agreement which is identified on the front hereof, the terms and conditions therein set forth shall be incorporated herein by references as though specifically set forth herein. Any provision herein which is inconsistent with the provisions of said overriding agreement is hereby amended to conform to said overriding agreement.

MODIFICATION AND WAIVER

Any alterations or modifications of this Contract shall be by mutual agreement of the parties and shall not be binding on Seller unless made in writing and agreed to by a duty authorized official of Seller.

No claim or right arising out of breach of this Contract can be discharged in whole or in part by waiver of renunciation of the claim or right unless the waiver or renunciation is in writing and signed by Seller.

REMEDIES

The remedies herein reserved to Seller shall be cumulative and additional to any other or further remedies provided in law or equity.